The client (Party A): According to the “Contract Law of the People's Republic of China†and other relevant laws and regulations, combined with the characteristics of residential decoration in this Municipality, Party A and Party B shall, on the basis of equality and voluntariness, agree to contract Party A to contract for Party A’s residential interior decoration works ( The related issues hereinafter referred to as "engineering" have reached the following agreement (including the annex to this contract and all supplementary contracts): First, the project address: ___________________________________; Second, the room specifications: room type __________ layer (style) ___________ room ____________ Hall __________ kitchen _____________ ________ balcony 1, _________ room, total __________ square meters; 2. _________ Hall, __________ square meters; 3, _______ kitchen, plan ________ square meters; 4, _______ bathroom, count _________ square meters; 5, __________ balcony, count __________ square meters; 6, other (indicated parts), total square meter. Total: construction area of ​​square meters. III. Construction Content: For details, please refer to "Household Decoration Construction Content List", Construction Process List and Construction Drawings Fourth, the project contracting method, the parties agreed to adopt the following __ (2) _____ kinds of contracting methods. (1) Party B works and packs all materials (see attached table: Party B provides a detailed list of decorative materials); (2) Party B shall provide contracted materials and accessories, and Party A shall provide the main materials (see Attached Table: List of Decoration Materials Provided by Party A; see Appendix: List of Decoration Materials Provided by Party B); (3) Party B shall provide contracted labor and Party A shall provide all materials (see attached table: List of Decoration Materials Provided by Party A). V. Project Commencement Date: 2004 6. Completion date of the project: 2004, January and May. Total days of the project: days Article 2: Construction Price Project price (amount in capital) ---- whole. (Including decoration accessories, labor costs, design fees, decoration garbage clearance freight, unloading fees, elevator freight charges, management fees, decoration pass card fees and deposits, etc.) Article 3: Quality Requirements 1. The varieties, specifications and names of the main materials used in the project are approved by both parties. Second, the project acceptance criteria, the two sides agreed to refer to the "residential decoration decoration acceptance standards" provisions. Third, quality inspection and supervision departments: Chongqing Interior Decoration Industry Association Home Decoration Professional Committee. 4. For materials and equipment purchased by Party A itself, the quality of the product shall be assumed by Party A; Party B shall be responsible for the construction quality. 5. If Party A hires engineering supervision, Party B must notify Party B before the construction of the project so as to facilitate the work connection. Article IV: Material Supply 1. Party B shall strictly follow the regulations stipulated by the State in the price regulations and implement the price of all the materials used in this contract. See the attachment of this contract for details. The materials provided by Party A shall be used in the decoration works stipulated in this contract, and shall not be used for other purposes without the consent of Party A. If Party B uses it for other purposes, Party B shall compensate Party A according to the double price of the misappropriated material. 2. Materials and equipment provided by Party B according to the contract (see attached table: List of Decoration Materials Provided by Party B). Accepted by both parties, the materials shall be signed and approved by Party A before construction; if it does not meet quality requirements or specifications If there is any difference, it shall be prohibited from use. If it is used, Party B shall be responsible for the losses caused to the project. 3. The materials and equipment provided by Party A according to the contract shall be qualified products that meet the design requirements, and shall be delivered on time to the site (see attached table: Party A provides decoration materials schedule), and the two parties jointly accept and handle the handover procedures; The materials and equipment supplied by Party A suffered a quality problem and the responsibility was borne by Party A. After the materials supplied by Party A are accepted by Party B, Party B shall be responsible for the safekeeping. If any loss is caused due to improper storage, Party B shall be responsible for compensation. Article 5: Payment Method 1. Once the contract is signed, Party A shall pay the construction fee __________ (capital ___________); when the progress of the construction period reaches ________________________ and is qualified by Party A, Party A shall pay the construction fee for the second time ______________ (capital: ___________________) When the construction schedule reaches _____________________ and is accepted by Party A, Party A pays the construction fee ____________ (uppercase: ________________) for the third time. Party A pays the construction fee for the fourth time. It is settled after the renovation project is completed and the experience is accepted. The amount is ________ (uppercase: ______________). Second, the remaining portion ___________ (uppercase: _________) of the remaining funds, as renovation risk gold, no project risk will be paid after three months (Note: The construction fee includes decoration accessories, labor costs, design fees, construction clear freight, unloading Fees, management fees, etc.). 3. Party A pays off the project price, Party B issues a unified invoice, and handles the transfer and issuance of the decoration project warranty card to Party A. (In the course of the project, Party A pays the item, and Party B receives the receipt.) 4. Party A's failure to pay on the due date of payment is a breach of contract. Party B has the right to stop the construction. When the acceptance of the project fails to settle the agreed project price, it shall not be delivered for use. Article 6: Project Duration First, due to delays due to the following reasons, confirmed by Party A, the duration of the corresponding delay: 1. Changes in project volume or design changes; 2. The materials and equipment selected by Party A shall be affected by quality failure and affect the quality and duration of the project. The rework cost shall be borne by Party A. Due to the quality accident caused by Party B's construction, the rework cost shall be borne by Party B and the duration shall not change. 3. During the construction, due to project quality problems and the disagreement between the two sides resulting in suspension of work, both parties did not follow the deadline for work delay or delay. The parties should actively request the mediation or arbitration departments of the relevant departments to coordinate and handle the disputes as soon as possible so as to continue the construction. IV. If Party A requires re-rework due to Party A's reasons, or Party A delays the construction period due to changes in the construction content, Party B shall not be liable. If Party B causes rework, Party B shall bear the responsibility and the duration shall not change. 5. During the construction, Party A shall notify the construction personnel without permission of Party B to notify the construction personnel of the unauthorized modification of the quality of the construction content and delay the construction period. Party A shall be responsible for itself. Article 7: Project Acceptance 1. After the completion of the project, Party B organizes Party A to perform the final acceptance. Both parties handle project settlement and handover procedures. Quality standards The construction quality of this project shall be implemented in accordance with the following ____________ criteria; 1) The contents of the construction drawings and design changes and the "Quality Acceptance Criterion of Chongqing Residential Decoration Engineering". 2) Both parties agree. 1. During the construction process, both parties disputed the quality of the project. The application was certified by the ________ department to the quality of the project. The cost of the certification was based on the principle of “who proposed to advanceâ€. If the quality of the project does not conform to the contractual standard after being certified, the cost of the certification shall be borne by the responsible party; if the project quality meets the contractual standards, the cost of the certification shall be borne by Party A. 2. Both Party A and Party B shall go through the inspection and acceptance procedures for concealed and intermediate works in a timely manner. Party A shall not participate in the concealed works and intermediate works on time. Party B may accept the inspection and Party A shall acknowledge it. If Party A asks for re-inspection, Party B shall perform the re-inspection as required. If the re-inspection is qualified, Party A shall bear the cost of re-inspection. If the re-inspection is caused, the construction period will be postponed. If the re-inspection fails, the inspection and rework cost shall be borne by Party B, but The duration should be postponed. 3. The two parties agreed to divide the construction quality into the following stages for acceptance of project quality. Party B shall notify Party A to participate in the inspection and acceptance two days in advance. 4. After the completion of the project, Party B shall notify Party A of the acceptance. Party A shall organize the inspection and acceptance within three days after receiving the acceptance notice and go through the acceptance and handover procedures. If Party A does not organize an acceptance within the specified time, Party B shall notify Party B in a timely manner and set an acceptance date, but Party A shall acknowledge the completion date. 5. After the completion acceptance of the project, Party B shall submit the project settlement statement and related materials to Party A. Party A shall complete the review within three days after receiving the above-mentioned information. No objection shall be filed within the time limit, and shall be deemed as the agreement. The agreement shall be settled within three days. . 6. The warranty period for this project is one year from the date of acceptance and acceptance by both parties. After the acceptance of the signature and settlement of the agreed amount, fill in the project warranty. 7. Acceptance is unqualified. Party B is responsible for rework. Party A may not use it, otherwise the use of the house is deemed as qualified. 8. Due to Party A's reason the project price is not settled, Party B is not responsible for the warranty. 9. If the project has not been accepted, Party A will use it in advance and there will be quality problems. Party A shall assume the responsibility. Article 8: Other matters First, the work of Party A 1. Before the start of construction ________ days, provide Party B with floor plans and water, electricity, and gas circuit diagrams approved by the realty management department, and submit site visits to Party B to create conditions for Party B's admission construction. Including: removal of furniture, furnishings, furniture or furnishings that are not easy to move in the room, as well as collection and concealment, so as not to affect the construction principle; 2. Responsible for providing water and power for use by Party B; (For construction purposes only, workers may not be used for personal use) 3. Responsible for coordinating the relationship between the decoration company and its neighbors; assisting Party B in performing on-site security, firefighting, and other work. If you need to temporarily use common parts during construction, please make a greeting to your neighbors. 4. If the original building or equipment pipeline is required, it shall be responsible for the approval procedures for the relevant departments to handle the response and bear the relevant expenses; Second, the work of Party B 1. Appointment (name) as the site representative, responsible for the performance of the contract, organize the construction according to the requirements, guarantee the quality and quantity of the construction tasks on time, and resolve all matters concerning the responsibility of Party B. 2. Strictly implement construction regulations and safety operation regulations, take charge of the safety of the construction site, prevent fires, certify posts, civilized construction, and prevent accidents such as pipeline blockage, water leakage, power outage, and damage to goods caused by construction and affect others. . In case of occurrence, it must be repaired or compensated as soon as possible. The construction site should be equipped with dry powder fire extinguishers. 3. Protect the furniture and furnishings in the original room to ensure the smooth flow of the indoor and sewer pipes, and handle the problems caused by the construction and the relationship with the surrounding units (residents). 4, to ensure the cleanliness of the construction site, do a good job of construction site security, garbage disposal. The equipment provided by Party A and the furniture, furnishings and other items piled on the site shall be properly protected and, if any, be compensated according to the price. 5. Without the consent of Party A, Party B shall, without authorization, renovate the original building structure and equipment pipelines, and Party B shall be responsible for the loss or accident (including fines) incurred therefrom and bear the losses. 6. Before the project completion has been transferred to Party A, it is responsible for the protection of all facilities on site and the finished engineering product. Should present its business license, membership certificate, or construction qualification; if it is a subordinate branch, it must also have a certificate from a superior company; the salesman must have a legal representative's commission certificate. 7. Undertook the warranty responsibility within the scope of decoration work, and the warranty period shall be three years from the date of acceptance of the completion of the project by Party A. Third, safety production and fire prevention 1. The construction drawings or instructions provided by Party A or Party B should be in accordance with Fire Regulations of the People's Republic of China and relevant fire protection design codes, which mainly include the unimpeded and qualified electrical lines, pipelines, tap water and other line pipelines. 2. During the construction period, Party B shall strictly comply with the "Safety Code for Construction and Installation Workers" and "Safety Code for Construction and Installation Workers" and pay attention to construction safety. In the course of construction, if a safety accident (including property damage, personal injury or death, etc.) or other losses occurs, Party B shall be responsible for 3. As a result of the drawings or practices provided by Party A, and in violation of the relevant safety operation regulations, fire prevention regulations and fire protection design specifications, a fire accident will occur. Party A shall bear all economic losses arising therefrom. 4. As Party B violates relevant safety operation regulations and fire control regulations in the construction and production process, resulting in safety or fire accidents, Party B shall bear all economic losses arising therefrom. Article 9: Liability for breach of contract After the contract comes into effect, during the performance of the contract, the parties who canceled the contract without authorization shall pay the other party as the breach of contract with 5% of the total amount of the contract. If the contract is cancelled without authorization and the actual damage caused by the other party exceeds the liquidated damages, compensation shall be made. Article 10: Dispute Resolution 1. During the performance period of the contract, if there is a dispute between the two parties, the two parties shall resolve the dispute without prejudice to the progress of the project. Or on the basis of this contract and the unified bid issued by Party B to the Chongqing Interior Decoration Industry Association Family Decoration Professional Committee to make a complaint. 2. If the parties are unwilling to resolve through negotiation or mediation, or if consultation or mediation fails to resolve, they may apply for arbitration in accordance with this contract. Article 10: Several specific provisions 1. The garbage generated due to the project shall be carried by Party B out of the construction site and shall be immediately transported to the designated place of the property. 2. During the construction period, Party A will hand over the door key to the representative of Party B - responsible for safekeeping. After the completion acceptance of the project, Party A shall be responsible for providing the new lock, which shall be responsible for the installation and use of Party B. 3. Party B shall carry out construction according to the contract and specifications. If Party A has special requirements, it shall notify Party B in written form before construction. After the request, Party B needs to agree, otherwise Party B may not handle it. Article 11: Changes and termination of the contract 1. After the contract has been signed and signed by both parties, both parties must strictly abide by it. If any party needs to change the content of the contract, it should sign a supplementary agreement after mutual agreement. If it is necessary to terminate the contract, the party that proposed the termination of the contract must submit it in written form. The liquidated damages shall be paid at 5% of the total price of the contract and the formalities for terminating the contract shall be handled. 2. In the course of construction, either party should terminate the contract and must submit it in writing to the other party. After the two parties agree to complete the liquidation formalities, after the conclusion of the termination agreement, the termination of the contract can be regarded as the dissolution of the contract. Article 12: The Contract Takes Effect 1. Both sides of this contract and the annexes of the contract shall be sealed by both parties and shall be effective after signature. Second, the supplementary contract and this contract have the same legal effect. Third, this contract (including the contract attachments, supplementary contracts) in one copy, A and B parties each hold one copy. Article 13: Supplementary Provisions 1. After the contract is signed, the project may not be subcontracted. Second, the contract attachment: Party A (owner): (signature) Party B: (signature) Remarks: Since the date of acceptance of completion, the warranty period for the calculation of decoration and decoration is three years, and the warranty period for hydropower projects and kitchen and toilet leakage protection works with waterproof requirements is five years; during the warranty period, due to the improper construction of Party B, quality problems will be caused. It must be repaired in a timely and unconditional manner. Construction Contract Decoration Decoration Interior Decorating Furniture Elevator Door Toilet Design Toilet Waterproof Toilet Waterproof Price Bathroom Door Bathroom Leakage Caterpillar Parts,Caterpillar Engine Parts,Cheap Caterpillar Parts,Caterpillar Forklift Parts JINING SHANTE SONGZHENG CONSTRUCTION MACHINERY CO.LTD , https://www.huaxinbrush.com
The undertaker (Party B):
This project designer: Contact phone:
Construction Manager: Contact Phone:
project:
Article 1: Project Overview
2. Force majeure;
3. Party A agrees with the other conditions for the extension of the construction period.
4. If Party A requires that the construction period is earlier than the contractual time, the agreement of Party B shall be obtained.
5. If Party A does not affect the construction period due to the failure of Party A to complete its due work, the construction period will be postponed. As Party A failed to pay the project price on schedule, the duration of the contract was postponed accordingly.
6. If the responsibility of Party B cannot be commenced on schedule or the stoppage of work is unreasonably affected, the construction period will not be postponed. If there is a problem with the quality of the project due to Party B's reasons, the rework cost shall be borne by Party B and the construction period shall not be postponed. 1% of the daily fee as a penalty.
1_______________________________2_____________________________________;
3_______________________________4____________________________________;
5_______________________________6___________________________________;
1. Party B's construction process steps;
2. Party A provides a detailed list of decoration materials;
3, Party B provides a detailed list of decoration materials;
Address of residence: Address of company:
Work unit: Legal representative:
Attorney: Attorney:
Telephone: Telephone:
Contract date: